Bill Text: TX HB2265 | 2023-2024 | 88th Legislature | Introduced

NOTE: There are more recent revisions of this legislation. Read Latest Draft

---

Bill Title: Relating to the award of compensatory damages caused by certain delays under governmental construction contracts.

Spectrum: Slight Partisan Bill (Republican 3-1)

Status: (Engrossed - Dead) 2023-05-24 - Placed on intent calendar [HB2265 Detail]

Download: Texas-2023-HB2265-Introduced.html

---

88R4436 JES-F
By: Leach H.B. No. 2265

A BILL TO BE ENTITLED
AN ACT
relating to the award of compensatory damages caused by certain
delays under governmental construction contracts.
BE IT ENACTED BY THE LEGISLATURE OF THE STATE OF TEXAS:
SECTION 1. Subchapter Z, Chapter 2252, Government Code, is
amended by adding Section 2252.909 to read as follows:
Sec. 2252.909. LIMITATION OF COMPENSATORY DAMAGES CAUSED BY
GOVERNMENTAL DELAYS IN CONSTRUCTION CONTRACTS PROHIBITED. (a) In
this section:
(1) "Contractor" means a person engaged in the
business of developing, constructing, fabricating, repairing,
altering, or remodeling improvements to real property.
(2) "Governmental entity" means:
(A) the state;
(B) a municipality, county, public school
district, or special-purpose district or authority;
(C) a district, county, or justice of the peace
court;
(D) a board, commission, department, office, or
other agency in the executive branch of state government, including
an institution of higher education as defined by Section 61.003,
Education Code;
(E) the legislature or a legislative agency; or
(F) the Supreme Court of Texas, the Texas Court
of Criminal Appeals, a court of appeals, or the State Bar of Texas
or another judicial agency having statewide jurisdiction.
(b) A construction contract between a governmental entity
and a contractor may not prohibit or limit the award of compensatory
damages to the contractor for a delay caused solely by the
governmental entity.
(c) This section may not be waived. A purported waiver of
this section in violation of this subsection is void.
SECTION 2. Section 2252.909, Government Code, as added by
this Act, applies only to a construction contract entered into on or
after the effective date of this Act.
SECTION 3. This Act takes effect September 1, 2023.